Terms & Conditions
Last Updated: June 9, 2026
Welcome to C&B Waterworks. By accessing or using this website, you agree to be bound by the following Terms & Conditions. If you do not agree with these terms, please do not use this website.
Website Use
This website is intended to provide information about our landscaping, lawn care, irrigation, hardscaping, maintenance, and related services.
You agree to use this website only for lawful purposes and in a manner that does not interfere with the operation of the website or the rights of other users.
Estimates and Service Information
Any pricing, project examples, service descriptions, timelines, or other information displayed on this website are provided for informational purposes only.
All landscaping projects are unique, and final pricing will be determined after a consultation, site visit, or formal estimate.
Submission of a contact form, quote request, or inquiry does not create a contractual relationship between you and the Company.
Quotes and Proposals
All quotes and proposals provided by the Company are subject to change based on site conditions, material availability, labor requirements, weather conditions, permitting requirements, and other unforeseen circumstances.
Written estimates are valid only for the period specified in the estimate.
Scheduling and Project Timelines
Project start dates and completion timelines are estimates only and may be affected by:
Weather conditions
Material availability
Permit approvals
Site accessibility
Unforeseen project conditions
Circumstances beyond our control
We will make reasonable efforts to communicate scheduling changes when necessary.
Payments
Payment terms for landscaping services will be outlined in individual project agreements or invoices.
Failure to make payments according to agreed terms may result in project delays, suspension of work, collection efforts, or additional fees where permitted by law.
Warranties
Any warranties offered by the Company will be provided in writing as part of a project agreement.
Plant material, sod, irrigation systems, hardscape installations, and other landscaping elements may be affected by weather, maintenance practices, soil conditions, pests, disease, acts of nature, or factors beyond our control.
Except where specifically stated in writing, no additional warranties are expressed or implied.
Intellectual Property
All content on this website, including but not limited to:
Logos
Branding
Text
Graphics
Images
Videos
Designs
Website content
is the property of C&B Waterworks and may not be copied, reproduced, distributed, or used without written permission.
Third-Party Links
This website may contain links to third-party websites for your convenience.
We do not control or endorse third-party websites and are not responsible for their content, privacy practices, products, or services.
Limitation of Liability
To the fullest extent permitted by law, C&B Waterworks shall not be liable for any direct, indirect, incidental, consequential, special, or punitive damages arising from:
Use of this website
Inability to access the website
Reliance on information provided on the website
Errors or omissions in website content
Temporary interruptions or technical issues
Website content is provided "as is" without warranties of any kind.
Indemnification
You agree to indemnify and hold harmless C&B Waterworks, its owners, employees, contractors, affiliates, and agents from any claims, damages, losses, liabilities, or expenses arising from your use of this website or violation of these Terms & Conditions.
Governing Law
These Terms & Conditions shall be governed by and construed in accordance with the laws of the State of [State], without regard to conflict of law principles.
Any disputes arising from these Terms & Conditions shall be resolved in the courts located within the applicable jurisdiction of Colorado.
Changes to These Terms
We reserve the right to modify these Terms & Conditions at any time without prior notice.
Updated versions will be posted on this page with a revised effective date.
Contact Information
If you have any questions regarding these Terms & Conditions, please contact:
C&B Waterworks
chad@cbwaterwork.com
(303) 994-3356